GEM

Urban Development Department Chhattisgarh Playground Merry Go Round Tender 2025 ISO/IS/Generic Safety Standards

Posted

24 Oct 2025, 11:10 pm

Deadline

14 Nov 2025, 06:00 pm

Location

JANJGIR-CHAMPA , CHHATTISGARH

Progress

Issue24 Oct 2025, 11:10 pm
AwardPending
Explore all 4 tabs to view complete tender details

Quantity

1

Bid Type

Two Packet Bid

Key Highlights

  • • Brand/OEM requirements: OEM turnover criteria; primary product category must meet specified turnover benchmarks
  • • Technical standards: explicit standards not listed; emphasis on generic safety and performance compliance
  • • Special clauses: turnkey SITC scope including operator training and statutory clearances, if any
  • • Eligibility: three-year turnover requirement (bidder and OEM); past project experience proof required
  • • Warranty/AMC: not specified in data; clarify during bid if required
  • • Penalties/LD: not specified in data; verify during schedule and contract terms
  • • Delivery/Installation: turnkey delivery, site installation and commissioning requirements
  • • Submission focus: demonstrate capability for SITC, training, and regulatory alignment

Categories 1

MERRY GO ROUND

Tender Overview

The procurement is for a Playground Merry Go Round (V2) under the Urban Development Department of Chhattisgarh. The scope covers Supply, Installation, Testing and Commissioning (SITC) and training of operators, with statutory clearances if required. The tender envisions a turnkey solution for a generic category item with emphasis on safety, durability, and compliance, and requires both bidder and OEM turnover benchmarks. The BOQ shows no items listed, indicating a broad specification framework rather than a fixed quantity. A key differentiator is the emphasis on completing SITC and operator training within a defined project window, aligned with compliant installation practices.

Technical Specifications & Requirements

  • Product: Playground Merry Go Round (V2) with safety-focused design
  • Key parameters: Overall diameter in meters, seating capacity and number of children on platform, and seat material for seated configurations
  • Material/finish: seat material details to be supplied; generic requirement implies weather-resistant, durable construction
  • Compliance: generic safety and performance standards; no explicit IS/ISI numbers provided in data
  • Scope elements: supply, installation, testing, commissioning, operator training, and statutory clearance coordination if applicable
  • Delivery readiness: turnkey delivery implies readiness for site installation and commissioning
  • BOQ: no listed items, suggesting a flexible specification aligned to site needs

Terms, Conditions & Eligibility

  • Scope includes SITC, operator training, and statutory clearance coordination
  • Turnover criteria: minimum average annual financial turnover over the last 3 years; detailed in bid document
  • OEM turnover criteria: OEM of offered product must meet turnover benchmarks over the last 3 years
  • Past project experience: documented proof via contracts, invoices, execution certificates or similar
  • Manufacturer/ bidder must meet experience criteria for supply and installation/commissioning of similar playground equipment

Key Specifications

  • Product/service: Playground Merry Go Round (V2) with generic safety/quality framework

  • Quantity/BOQ: No items listed; flexible scope based on site/specs

  • Turnover: bidder and OEM average annual turnover criteria specified in bid

  • Experience: proof of past supply/install/commissioning of similar playground equipment

  • Standards: generic safety/compliance terms; explicit standards not provided in data

  • Delivery: turnkey SITC including operator training and regulatory clearance coordination

Terms & Conditions

  • Scope requires SITC plus operator training and potential statutory clearances

  • 3-year turnover criterion for bidder and OEM with documentary evidence

  • Past project experience proof via contracts, invoices or client execution certificates

Important Clauses

Payment Terms

Not specified in data; bidders should confirm payment milestones and any advance or milestone payments in bid submission

Delivery Schedule

Turnkey SITC with installation and commissioning; precise timelines to be confirmed in bid documents

Penalties/Liquidated Damages

No LD details provided; bidders should seek explicit LD and performance bond terms in tender documents

Bidder Eligibility

  • Three-year turnover proof for bidder and OEM

  • Past experience in supply/installation/commissioning of similar playground equipment

  • Ability to provide SITC including operator training and regulatory clearances

Technical Specifications 1 Item

Item #1 Details

View Catalog
Category Specification Requirement
GENERIC General Requirements of the Play Ground Merry Go Round Conforming to Play Ground Merry Go Round for Parks and Open spaces - The equipment conforming to IS 6869 : Part 1, Play Ground Merry Go Round for Schools - The equipment conforming to IS 8404 : Part 1
GENERIC Types of Playground Merry Go Round Platform Merry Go Round, Seated Merry Go Round With Platform, Seated Merry Go Round Without Platform
GENERIC No of children capacity on the platform / Total seating capacity 4, 5, 6, 7, 8, 10
GENERIC Material of the Seat in the case of Seated Merry Go Round With Platform and Without Platform Fiber-Reinforced Plastic (FRP), High-Density Polyethylene (HDPE), Steel/Iron conforming to IS 6869 : Part 1/IS 8404 : Part 1, NA ( In case of Platform Merry Go Round)
GENERIC Overall Diameter of Playground Merry Go Round (In Meter "m") 1.5 m to 2 m, 2.1 m to 2.5 m, 2.6 m to 3.0 m

AI-Powered Bidder Prediction

Companies most likely to bid

Unlock Bidder Insights

AI predictions on likely bidders

Required Documents

1

GST registration

2

PAN card

3

Audited financial statements or CA certificate for turnover criteria (last 3 years)

4

Past project experience documents: contracts, invoices, execution certificates

5

OEM authorization letter or vendor declarations for primary product

6

Technical compliance certificates or product specifications (if available)

7

Any statutory clearance certificates (if required) and training plan

8

Bid security/EMD documentation (as specified in bid document)

Frequently Asked Questions

How to bid for the playground merry go round tender in Chhattisgarh 2025

Bidders must meet turnover criteria for both bidder and OEM, provide past project experience with contracts and invoices, and submit GST, PAN, and financial statements. The scope includes SITC and operator training; ensure compliance with generic safety standards and provide an installation plan.

What documents are required for the Chhattisgarh playground tender submission

Submit GST registration, PAN card, three-year turnover certificates or CA-certified turnover, past project experience proofs (contracts or execution certificates), OEM authorizations, technical compliance certificates, and EMD documentation. Include training plan and statutory clearance evidence if applicable.

What are the technical specifications for the merry go round in this tender

Specifications specify a Play Ground Merry Go Round (V2) with overall diameter in meters, seating capacity, number of children on platform, and seat material. Exact dimensions and materials are not disclosed; bidders must align design to safety and durability expectations and provide compliant test data.

What is the expected scope of supply for the playground equipment tender

Scope comprises Supply, Installation, Testing and Commissioning of the Merry Go Round, plus Training of operators and providing any required statutory clearances. bidders should present an end-to-end SITC plan with timelines and post-installation support options.

What are the turnover criteria for bidders and OEMs in this tender

Bidders must show minimum average annual turnover over the last three financial years; OEMs must meet the same turnover threshold for the supplied product category. Document turnover via audited balance sheets or CA certificate and upload with bid.

When is the delivery/completion timeline for the playground project in CG

Exact delivery timelines are not disclosed; the tender mandates turnkey SITC including installation and commissioning. Respondents should propose a detailed project schedule with milestones aligned to site readiness and training sessions.

What standards or certifications are required for the playground equipment

The tender mentions generic safety standards without listing ISI/ISO numbers. Bidders should confirm compliance with local safety norms, provide any available conformity certificates, and submit product specifications demonstrating safe, durable, weather-resistant design.

What documents prove past experience for similar playground projects

Acceptable proofs include contract copies with invoices and bidder self-certification, execution certificates from clients, third-party inspection notes, or other contract execution documents demonstrating deployment of similar equipment.

Similar Tenders

Garden Swings,Outdoor Slide (V2),Garden Swings,Outdoor Slide (V2),Play Ground Merry Go Round (V2),

Sports Youth and Cultural Activities Department Gujarat

BANASKANTHA, GUJARAT

EMD: ₹29,997
Est: ₹10.0 L
View Details

Garden Swings,Outdoor Slide (V2),Garden Swings,Outdoor Slide (V2),Play Ground Merry Go Round (V2),

Sports Youth and Cultural Activities Department Gujarat

BANASKANTHA, GUJARAT

EMD: ₹29,997
Est: ₹10.0 L
View Details