Indian Army UAV Day/Night System Tender Jammu Kashmir 2026 - 20 km RG Complete System with 4MP PTZ, NVR 32 Channel 4K and 55 Inch LED TV
Bid Publish Date
04-Jul-2026, 1:32 pm
Bid End Date
24-Jul-2026, 12:00 pm
EMD
₹3,21,000
Value
₹64,20,000
Location
Progress
RATender Overview
The Indian Army (Department Of Military Affairs) invites bids for a complete SVL UAV day and night system package in Jammu, Jammu & Kashmir (postal code 180001). Estimated value is ₹6,420,000 with an EMD of ₹321,000. Scope includes supply, installation, testing, commissioning, operator training, and statutory clearance where required. Includes diverse components such as a day/night drone system with RG 20 km, a 10 inch FPV Kamikaze drone, a 4MP PTZ camera with 180m IR capability, NVR 32 Channel 4K, and ancillary items like 55 inch LED TV, Media Converter, multiple PoE switches, Cat6 cable (305m), and a 10 KVA two-phase automatic voltage stabilizer. The “OPTION CLAUSE” allows up to 50% quantity variations at contract rates during and after delivery, with minimum 30 days added delivery time if required. Delivery and installation address is specified as the project location in the buyer’s terms. Scope includes training and statutory clearances, with a mandatory Manufacturer Authorization for OEMs or distributors.
Technical Specifications & Requirements
- Product family: SVL UAV day/night complete system with RG 20 km range, plus supplementary components (10" FPV Kamikaze drone, 4MP PTZ camera, 180m IR, NVR 32-channel 4K).
- Essential peripherals: 55 inch LED TV, Media Converter (Fiber to Ethernet), PoE Switches (5-port, 16-port, 8-port), Cat6 cable (305m box).
- Power and reliability: Automatic Voltage Stabilizer 10 KVA, 2-Phase; Power cable specification: 25 sq mm.
- Installation scope: supply, installation, testing, commissioning, operator training; includes any statutory clearances.
- Documentation: OEM authorization required for authorized distributors; NDA and non-disclosure compliance.
- No explicit performance thresholds given; bidders must align to scope and deliver integrated security-telemetry suite.
Terms, Conditions & Eligibility
- EMD: ₹321,000; submission via online/offline as specified; bid must include EMD details.
- Delivery terms: delivery period per ATC; option clause allows up to 50% quantity increase/decrease at contracted rates; extension rules apply with minimum 30 days.
- Manufacturer Authorization: required for OEM or authorized distributors; provide certificate with contact details.
- Non-disclosure: bidder must sign NDA on letterhead; restrict disclosure of contract details.
- Scope: supply, installation, testing, commissioning, operator training, and statutory clearances if any; all costs included in bid price.
Key Specifications
-
UAV system: day/night SVL with RG up to 20 km
-
Drone payload: 10 inch FPV Kamikaze platform
-
Camera: 4MP PTZ with 180m IR range
-
NVR: 32 Channel with 4K recording capability
-
Display/Networking: 55 inch LED TV, Media Converter Fiber to Ethernet
-
Networking: PoE Switches (5-port, 16-port, 8-port) and Cat6 Cable 305m box
-
Power: Automatic Voltage Stabilizer 10 KVA, 2 Phase and 25 sq mm power cable
-
Scope: Supply, Installation, Testing, Commissioning, Operator Training, and Statutory Clearances if any
-
Compliance: OEM Authorization required; NDA to be signed; delivery terms allow up to 50% quantity variation
Terms & Conditions
-
EMD amount: ₹321,000 with acceptable payment method
-
Delivery period adjustable under option clause up to 50% quantity change
-
OEM authorization and non-disclosure compliance mandatory
-
Scope includes installation, commissioning, and operator training
-
Statutory clearances, if any, to be provided by bidder
Important Clauses
Payment Terms
Bid includes all costs; payment terms to be as per clause in ATC; EMD must be provided with bid
Delivery Schedule
Delivery period as per original order; option to increase/decrease quantity up to 50%; extended delivery time subject to minimum 30 days
Penalties/Liquidated Damages
LD provisions apply as per buyer terms; detailed LD rate to be specified in ATC and contract
Bidder Eligibility
-
Proven experience in supplying UAV/security surveillance systems for government entities
-
Financial capacity to support ₹6.42 million contract value
-
Authorized OEM/Distributor status with valid authorization certificate
Technical Results
| S.No | Seller | Item | Date | Status |
|---|---|---|---|---|
| 1 | ASTROX AEROSPACE PRIVATE LIMITED Under PMA | - | 13-07-2026 13:48:49 | |
| 2 | ENORD PRIVATE LIMITED Under PMA | - | 24-07-2026 11:44:40 | |
| 3 | FUTURE TECHNOLOGY Under PMA | - | 23-07-2026 15:03:55 | |
| 4 | GARUDA AEROSPACE LIMITED Under PMA | - | 14-07-2026 11:18:02 | |
| 5 | HAZZALE BLUE TRADING PRIVATE LIMITED Under PMA | - | 23-07-2026 11:06:49 | |
| 6 | K R ENTERPRISES Under PMA | - | 23-07-2026 22:34:03 | |
| 7 | M.D. ENTERPRISE Under PMA | - | 11-07-2026 16:46:11 | |
| 8 | Mahadev Enterprises Under PMA | - | 23-07-2026 15:15:43 | |
| 9 | MCI DEFENCE TECHNOLOGIES PRIVATE LIMITED Under PMA | - | 24-07-2026 11:29:45 | |
| 10 | PRYM AEROSPACE PRIVATE LIMITED Under PMA | - | 09-07-2026 11:33:46 | |
| 11 | SAFE TECH SOLUTIONS Under PMA | - | 24-07-2026 11:35:56 |
Financial Results
| Rank | Seller | Price | Item |
|---|---|---|---|
| L1 | FUTURE TECHNOLOGY(MII) Under PMA | Item Categories : Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time,10 inch FP | |
| L2 | Mahadev Enterprises (MII) Under PMA | Item Categories : Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time,10 inch FP | |
| L3 | K R ENTERPRISES (MII) Under PMA | Item Categories : Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time,10 inch FP | |
| L4 | SAFE TECH SOLUTIONS (MII) Under PMA | Item Categories : Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time,10 inch FP |
Reverse Auction Schedule
Start
18-Sep-2026, 8:00 pm
End
19-Sep-2026, 8:00 pm
Duration: 24 hours
Reverse Auction Document
✅ RA concluded. Check financial results for final rankings.
Tender Data
Bid Details
Quantity
1555
Category
Power Management System
Bid Type
Two Packet Bid
Bid Validity
180 (Days)
Bid Type
Service
Evaluation
Total value wise evaluation
Inspection Required
No
RA Qualification Rule
50% Lowest Priced Technically Qualified Bidders
Tech Clarification Time
2 Days
Preference & Exemptions
EMD Required
Yes
MII Purchase Preference
Yes
MII Preference Band
L1+20%
MSE Purchase Preference
Yes
MSE Preference Band
L1+15%
MSE Exemption/Relaxation
Yes
Startup Exemption/Relaxation
No
Bid Splitting Applied
No
Requirements
Past Performance
30 %
Arbitration Clause
No
Mediation Clause
No
Additional Tender Data
Commercial Details
Tender Category
Goods
Bid To RA
No
Bid To RA Enabled
Yes
Item Category
Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time , 10 inch FPV Kamikaze Drone , PTZ Camera 4MP 180m IR , Power Management System , NVR 32 Channel 4K , Power Cable 25 sq mm 4 Aluminium , LED TV 55 inch , Media Converter Fiber to Ethernet , PoE Switch 5 Port , PoE Switch 16 Port , PoE Switch 8 Port , Cat6 Cable 305m Box , Automatic Voltage Stabilizer 10 KVA 2 Phase
Advisory Bank
State Bank of India
ePBG Percentage
3%
ePBG Duration (Months)
14
Pre-Bid & Qualification
Pre-Bid Date
09-07-2026 11:00:00
Pre-Bid Venue
Pre bid meeting will be carried out virtually through VC. Contact No of Project Officer is 8860688642 (Whatsapp Only)
Delivery Details
Max Delivery Days
30
Delivery Locations
1
Delivery Cities
Jammu
Delivery Locations
| Consignee | Address | City | State | Pincode | Quantity | Delivery Days | Additional Requirement |
|---|---|---|---|---|---|---|---|
| - | Jammu | Jammu | - | - | 1 | 30 | - |
Authority Records
BID & GeM Expert Consultancy
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Documents 5
GeM-Bidding-9470217.pdf
Main Document
BOQ Document
BOQ
BOQ Document
BOQ
Other Documents
OTHER
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
Bill of Quantities (BOQ)
13 Items Sign in to view GEM price trends Sign in for GEM prices
Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time
Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time
10 inch FPV Kamikaze Drone
10 inch FPV Kamikaze Drone
PTZ Camera 4MP 180m IR
PTZ Camera 4MP 180m IR
Power Management System
Power Management System
NVR 32 Channel 4K
NVR 32 Channel 4K
Power Cable 25 sq mm 4 Aluminium
Power Cable 25 sq mm 4 Aluminium
LED TV 55 inch
LED TV 55 inch
Media Converter Fiber to Ethernet
Media Converter Fiber to Ethernet
PoE Switch 5 Port
PoE Switch 5 Port
PoE Switch 16 Port
PoE Switch 16 Port
PoE Switch 8 Port
PoE Switch 8 Port
Cat6 Cable 305m Box
Cat6 Cable 305m Box
Automatic Voltage Stabilizer 10 KVA 2 Phase
Automatic Voltage Stabilizer 10 KVA 2 Phase
| Item # | Title | Description | Quantity | Unit | Consignee | Delivery (Days) | Price Trends |
|---|---|---|---|---|---|---|---|
| 1 | Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time | Svl UAV Day and Ni with Rg 20 Km Complete sys with day Thermal Camera 35 Min Flight Time | 1 | nos | 14jatbuyer | 30 | |
| 2 | 10 inch FPV Kamikaze Drone | 10 inch FPV Kamikaze Drone | 10 | nos | 14jatbuyer | 30 | |
| 3 | PTZ Camera 4MP 180m IR | PTZ Camera 4MP 180m IR | 18 | nos | 14jatbuyer | 30 | |
| 4 | Power Management System | Power Management System | 1 | nos | 14jatbuyer | 30 | |
| 5 | NVR 32 Channel 4K | NVR 32 Channel 4K | 2 | nos | 14jatbuyer | 30 | |
| 6 | Power Cable 25 sq mm 4 Aluminium | Power Cable 25 sq mm 4 Aluminium | 1,500 | mtr | 14jatbuyer | 30 | |
| 7 | LED TV 55 inch | LED TV 55 inch | 2 | nos | 14jatbuyer | 30 | |
| 8 | Media Converter Fiber to Ethernet | Media Converter Fiber to Ethernet | 10 | pair | 14jatbuyer | 30 | |
| 9 | PoE Switch 5 Port | PoE Switch 5 Port | 5 | nos | 14jatbuyer | 30 | |
| 10 | PoE Switch 16 Port | PoE Switch 16 Port | 1 | nos | 14jatbuyer | 30 | |
| 11 | PoE Switch 8 Port | PoE Switch 8 Port | 2 | nos | 14jatbuyer | 30 | |
| 12 | Cat6 Cable 305m Box | Cat6 Cable 305m Box | 2 | nos | 14jatbuyer | 30 | |
| 13 | Automatic Voltage Stabilizer 10 KVA 2 Phase | Automatic Voltage Stabilizer 10 KVA 2 Phase | 1 | nos | 14jatbuyer | 30 |
Categories
30
Corrigendum Updates
3 Updates Update
Update
Extended Deadline
24-Jul-2026, 6:30 am
Opening Date
24-Jul-2026, 7:00 am
Update
Extended Deadline
14-Jul-2026, 3:30 pm
Opening Date
14-Jul-2026, 4:00 pm
Required Documents
GST Registration Certificate
Permanent Account Number (PAN) Card
Experience Certificates for similar UAV/Video Surveillance projects
Financial Statements (last 3 years) or equivalent financials
EMD submission document (₹321,000) via DD/online payment
Technical bid documents demonstrating compliance with system specs
OEM Manufacturer Authorization or Authorized Distributor Certificate
Non-Disclosure Declaration on bidder letterhead
Any statutory clearances required by local authorities
ATC file or document referenced by buyer terms (ATC details)
Frequently Asked Questions
Key insights about JAMMU AND KASHMIR tender market
How to bid for the UAV day/night system tender in Jammu?
Bidders must meet eligibility criteria for this Indian Army procurement in Jammu. Submit GST, PAN, experience certificates, and financials, plus EMD of ₹321,000. Provide OEM authorization, NDA on letterhead, and technical compliance documents. Ensure delivery and installation scope aligns with the ATC terms.
What documents are required for the UAV procurement in Jammu & Kashmir?
Required documents include GST certificate, PAN, last 3 years financials, experience certificates for similar projects, EMD ₹321,000, OEM authorization, NDA, and technical bid detailing compliance with the day/night UAV system, NVR 32-channel 4K, and associated peripherals.
What are the key technical specifications for the UAV system in this tender?
Key specs include a day/night SVL UAV with 20 km RG range, 10 inch FPV Kamikaze drone, 4MP PTZ camera with 180 m IR, 32-channel 4K NVR, 55" LED TV, PoE switches, Cat6 cables, and a 10 KVA two-phase stabilizer. OEM authorization is mandatory; NDA compliance required.
When is the delivery and installation timeline for the Jammu UAV contract?
Delivery timing follows the original delivery order with extension rules permitting up to 50% quantity changes. If extended, additional time equals (Increased quantity ÷ Original quantity) × Original delivery period, minimum 30 days. Actual dates to be in the purchase order.
What is the EMD amount for the Indian Army UAV tender in Jammu?
The Earnest Money Deposit required is ₹321,000. It should be submitted along with the bid via online payment or demand draft as per the tender ATC requirements. Ensure the EMD covers bid validity and contract obligations.
What are the OEM authorization requirements for bidders?
Bidders must provide Manufacturer Authorization or OEM certification with complete contact details, including name, designation, address, email, and phone number, proving authorized status to supply the UAV system and peripherals.
What scope of supply is included in the UAV project in Jammu?
Scope includes supply, installation, testing, commissioning, operator training, and statutory clearances if applicable, ensuring turnkey readiness. All components, including NVR, PTZ camera, PoE switches, and power stabilizers, must be installed and verified by the vendor.