Indian Army UAV Structural Components Tender Department of Military Affairs India 2026 - 13 inch H Frame & 8mm Brushless Motor
Bid Publish Date
29-Aug-2026, 5:51 pm
Bid End Date
08-Sep-2026, 6:00 pm
Value
₹1,47,390
Location
Progress
Tender Overview
Organization: Indian Army, Department of Military Affairs. Product/Service: UAV structural components including H Frame 13 inch 8mm, Brushless Motor 900 KVA, FPV Rotor Blades 13 in, Integrated UAV Control Board 80A, Starlight FPV Camera Module v1, UAV Video Broadcast Unit 13w, ELRS Receiver Unit 100MW, 10000mAh LiPo Battery Module 8S2P, Remote Payload Release Unit, GPS, Circular Polarized FPV Antenna V2, and UAV Analog Vision and Control System. Estimated Value: ₹147,390. Location: Not specified. Scope: Procurement of UAV structural and electronic components under a single tender with multiple line items. The bid allows quantity adjustments of up to ±25% and extended delivery windows in line with option clauses. This tender emphasizes delivery timing rules aligned to original and extended periods. Unique clause: option-based quantity variation at contracted rates. Tender mentions no explicit technical specs in the data, but items indicate a complete UAV payload and control suite.
Technical Specifications & Requirements
- Product categories: UAV structural framework, brushless motors, FPV components, control boards, camera module, video broadcast, ELRS receiver, LiPo batteries, remote payload release, GPS, FPV antennas, and analog vision/control system.
- Estimated value: ₹147,390.
- Delivery terms: Option clause permits up to 25% quantity variation during contract; delivery period starts from last date of original delivery order; extended period calculations based on increased quantity with a minimum of 30 days.
- Standards/Compliance: No explicit standards listed in the data; bidders should infer compatibility across UAV components and ensure integration readiness with the Indian Army’s system architecture.
- Quality/Testing: Not specified; bidders should propose testing plans for electronic modules and battery packs.
- OEM/Brand: No specific brand restrictions mentioned.
- Scope nuance: 12 BOQ items exist, but all items are listed as N/A, indicating possible bundled procurement or placeholder items.
Terms, Conditions & Eligibility
- EMD: Not specified in the data. bidders should verify required security deposit with the buyer.
- Delivery: Delivery periods governed by option clause; minimum extension formula ensures extended delivery feasibility.
- Payment terms: Not specified in the data; bidders should confirm payment milestones with Indian Army procurement.
- Documents: Not specified; bidders should prepare GST, PAN, experience certificates, financials, OEM authorizations, and technical bid documents per standard defense tenders.
- Warranty/Penalties: Not specified; bidders should seek clarity on warranty terms and LD penalties in the final terms.
Key Specifications
-
UAV structural components: 13 inch H Frame, 8mm hardware
-
Brushless Motor: 900 KVA rating
-
FPV Rotor Blades: 13 inches
-
Integrated UAV Control Board: 80A capacity
-
Starlight FPV Camera Module v1
-
UAV Video Broadcast Unit: 13W
-
ELRS Receiver Unit: 100MW
-
Battery: 10000mAh LiPo, 8S2P configuration
-
Remote Payload Release Unit
-
GPS module
-
Circular Polarized FPV Antenna V2
-
UAV Analog Vision and Control System
Terms & Conditions
-
Option Clause permits ±25% quantity variation at same rates
-
Delivery period tied to last date of original ODO with adjustments
-
Extended delivery time calculated as (Increase/Original) × Original days, min 30 days
-
Buyer reserves rights to modify quantity within contract term
-
No tender ID, dates, or location to be disclosed in public sections
Important Clauses
Delivery Schedule
Delivery starts after original delivery order; extended schedules allowed with formula and minimum 30 days
EMD
Exact EMD amount to be confirmed; bidders must submit EMD as per final Terms
Payment Terms
Payment terms to be finalized; ensure alignment with defense procurement norms
Bidder Eligibility
-
Experience in supplying UAV components or defense-grade hardware
-
Compliance with GST and financial stability requirements
-
OEM authorization for critical components where applicable
Tender Data
Bid Details
Quantity
18
Category
UAV Structural H Frame 13 inch 8mm
Bid Type
Two Packet Bid
Bid Validity
30 (Days)
Bid Type
Service
Evaluation
Total value wise evaluation
Inspection Required
No
Tech Clarification Time
2 Days
Preference & Exemptions
EMD Required
No
MII Purchase Preference
No
MSE Purchase Preference
Yes
MSE Preference Band
L1+15%
MSE Exemption/Relaxation
No
Startup Exemption/Relaxation
No
Bid Splitting Applied
No
Requirements
Past Performance
20 %
Arbitration Clause
No
Mediation Clause
No
Additional Tender Data
Commercial Details
Tender Category
Goods
Bid To RA
No
Bid To RA Enabled
No
Item Category
UAV Structural H Frame 13 inch 8mm , Brushless Motor 900 KVA , FPV Rotor Blades 13 inche , Integrated UAV Control Board 80A , Starlight FPV Camera Module v1 , UAV Video Broadcast Unit 13w , ELRS Receiver Unit 100MW , 10000mAh LiPo Battery Module 8S2P , Remote Payload Release Unit , GPS , Circular Polarized FPV Antenna V2 , UAV Analog Vision and Control System
Delivery Details
Max Delivery Days
15
Delivery Locations
1
Delivery Cities
Baramulla
Delivery Locations
| Consignee | Address | City | State | Pincode | Quantity | Delivery Days | Additional Requirement |
|---|---|---|---|---|---|---|---|
| - | Baramulla | Baramulla | - | - | 1 | 15 | - |
Authority Records
BID & GeM Expert Consultancy
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Documents 4
GeM-Bidding-9815256.pdf
Main Document
BOQ Document
BOQ
BOQ Document
BOQ
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
Bill of Quantities (BOQ)
12 Items Sign in to view GEM price trends Sign in for GEM prices
UAV Structural H Frame 13 inch 8mm
UAV Structural H Frame 13 inch 8mm
Brushless Motor 900 KVA
Brushless Motor 900 KVA
FPV Rotor Blades 13 inche
FPV Rotor Blades 13 inche
Integrated UAV Control Board 80A
Integrated UAV Control Board 80A
Starlight FPV Camera Module v1
Starlight FPV Camera Module v1
UAV Video Broadcast Unit 13w
UAV Video Broadcast Unit 13w
ELRS Receiver Unit 100MW
ELRS Receiver Unit 100MW
10000mAh LiPo Battery Module 8S2P
10000mAh LiPo Battery Module 8S2P
Remote Payload Release Unit
Remote Payload Release Unit
GPS
GPS
Circular Polarized FPV Antenna V2
Circular Polarized FPV Antenna V2
UAV Analog Vision and Control System
UAV Analog Vision and Control System
| Item # | Title | Description | Quantity | Unit | Consignee | Delivery (Days) | Price Trends |
|---|---|---|---|---|---|---|---|
| 1 | UAV Structural H Frame 13 inch 8mm | UAV Structural H Frame 13 inch 8mm | 1 | pieces | mohit651 | 15 | |
| 2 | Brushless Motor 900 KVA | Brushless Motor 900 KVA | 4 | pieces | mohit651 | 15 | |
| 3 | FPV Rotor Blades 13 inche | FPV Rotor Blades 13 inche | 4 | pieces | mohit651 | 15 | |
| 4 | Integrated UAV Control Board 80A | Integrated UAV Control Board 80A | 1 | pieces | mohit651 | 15 | |
| 5 | Starlight FPV Camera Module v1 | Starlight FPV Camera Module v1 | 1 | pieces | mohit651 | 15 | |
| 6 | UAV Video Broadcast Unit 13w | UAV Video Broadcast Unit 13w | 1 | pieces | mohit651 | 15 | |
| 7 | ELRS Receiver Unit 100MW | ELRS Receiver Unit 100MW | 1 | pieces | mohit651 | 15 | |
| 8 | 10000mAh LiPo Battery Module 8S2P | 10000mAh LiPo Battery Module 8S2P | 1 | pieces | mohit651 | 15 | |
| 9 | Remote Payload Release Unit | Remote Payload Release Unit | 1 | pieces | mohit651 | 15 | |
| 10 | GPS | GPS | 1 | pieces | mohit651 | 15 | |
| 11 | Circular Polarized FPV Antenna V2 | Circular Polarized FPV Antenna V2 | 1 | pieces | mohit651 | 15 | |
| 12 | UAV Analog Vision and Control System | UAV Analog Vision and Control System | 1 | pieces | mohit651 | 15 |
Categories
23
🤖 AI-Powered Bidder Prediction
Discover companies most likely to bid on this tender
Required Documents
GST registration certificate
Permanent Account Number (PAN) card
Experience certificates for UAV component supply
Financial statements (audited/unaudited as applicable)
EMD/Security deposit proof (as per final Terms)
Technical bid documents illustrating component compatibility
OEM authorizations or authorized distributor letters
Any prior contract performance certificates
Product datasheets and compatibility matrices
Frequently Asked Questions
Key insights about JAMMU AND KASHMIR tender market
How to bid for the Indian Army UAV components tender in India 2026?
Bidders should prepare GST, PAN, financial statements, EMD proof, and OEM authorizations. The tender specifies an option clause allowing ±25% quantity changes and delivery extensions. Ensure your technical bid demonstrates compatibility across the UAV set: 13 inch frame, 80A control board, 13W video unit, 100MW ELRS, and 8S2P LiPo battery. Submit all mandatory documents and comply with delivery terms.
What documents are required for the UAV procurement bid in India 2026?
Required documents include GST registration, PAN card, notarized experience certificates for UAV components, audited financial statements, EMD proof, OEM authorization letters, technical compliance sheets, and product datasheets showing integration capability with control boards and FPV modules used by the Indian Army.
What are the key technical specs for the UAV modules in this tender?
Key components include 13 inch UAV rotor blades, 8mm frame hardware, 900 KVA brushless motors, 80A UAV control board, Starlight FPV Camera Module v1, 13W video broadcast unit, 100MW ELRS receiver, and a 10000mAh LiPo 8S2P battery. Ensure compatibility and wiring diagrams align with standard defense interfaces.
When is the delivery deadline for the UAV components tender in India?
Delivery timing follows the option clause. Initial delivery starts from the last date of the original order; extended delivery periods are calculated per additional quantity with a minimum of 30 days, and may extend to original delivery period depending on order adjustments.
What are the payment terms for the Indian Army UAV procurement?
Final payment terms are not specified in the data; bidders should await confirmation. Typically defense tenders follow milestone-based payments with potential upfront or staging payments; ensure clarity on payment milestones, acceptance criteria, and any performance-related incentives before submission.
What standards or certifications are required for UAV components tender 2026?
No explicit standards are listed in the data. Bidders should align components with general defense interoperability, request OEM certifications, ensure safety compliance for LiPo batteries, and obtain any necessary supplier declarations. Confirm ISI/ISO where applicable once terms are finalized.
How to verify EMD requirements for the UAV tender in India?
EMD amount is not specified publicly. Bidders must check the final Terms for the exact EMD value and acceptable payment methods (DD/online). Prepare EMD certificates, deposit proof, and ensure eligibility criteria are met with audited financials and experience certificates.
What is the scope of quantity variation under the option clause?
The Purchaser may increase or decrease quantity up to 25% of the bid quantity at contract placement and during the currency of the contract. Delivery time extensions follow a formula: (Increased quantity ÷ Original quantity) × Original period, with a 30-day minimum.