Indian Army UAV Drone Repair Services Tender Udhampur Jammu & Kashmir 2026
Bid Publish Date
06-Oct-2026, 6:25 pm
Bid End Date
17-Oct-2026, 7:00 pm
Value
₹1,10,000
Location
Progress
Tender Overview
Organization: Indian Army (Department Of Military Affairs) seeking repair of UAV drone services in UDHAMPUR, JAMMU & KASHMIR - 182101. Estimated value: ₹110,000. Procurement category: Custom Bid for Services. No BOQ items currently listed, indicating a service-market scope for maintenance/repair rather than a full parts purchase. Unique context includes mandatory certification uploads per Buyer Added Terms, signaling strict compliance and verifiable credentials. This tender targets skilled drone repair vendors capable of meeting military service quality expectations within a defined geographic location.
Technical Specifications & Requirements
- No formal technical specifications published in the tender data.
- The scope is restricted to repair/maintenance of UAV drones; bidders should anticipate operational repair capabilities, diagnostics, and replacement handling.
- Evolving requirement to upload certificates with the bid (per terms). Expect potential minimum competency checks and security/compliance verifications typical for armed forces service contracts.
- Given the absence of BOQ items, focus on bidders’ ability to respond quickly, provide service-level response times, and demonstrate prior UAV maintenance experience.
- Emphasize readiness to operate within Udhampur, JK jurisdiction and adhere to Indian Army procurement norms.
Terms, Conditions & Eligibility
- EMD: Not specified in the data; verify in tender document or ATC for actual deposit requirements.
- Certificates: Mandatory uploads of defined certificates/documents; non-submission may lead to rejection.
- Delivery/Service Window: Service delivery timelines to be clarified in the final bid package; anticipate on-site or near-site repairs.
- Approvals & Compliance: Expect adherence to security clearances and government procurement policies; OEM authorizations may be required for UAV repair.
Key Specifications
-
Product/Service Names: UAV drone repair and maintenance services
-
Estimated Value: ₹110,000
-
Location: Udhampur, Jammu & Kashmir 182101
-
Category: Custom Bid for Services - UAV repair
-
Standards/Certifications: To be confirmed in bid documents; prepare for security/compliance certifications
-
Delivery: On-site or local repair capability within UDHK region; timelines to be defined
-
Experience: Demonstrated UAV repair capability; prior government/military service preferred
Terms & Conditions
-
EMD amount not listed in basic data; confirm in official bid documents
-
Upload required certificates/documents with bid per Buyer Added Terms
-
No BOQ items; scope is service-based repair of UAV drones
-
Delivery timelines and payment terms to be clarified in subsequent ATC
-
Compliance with security and OEM-authorized service norms may apply
Important Clauses
Payment Terms
Specific payment terms will be defined in the ATC; bidders should anticipate milestone-based or post-service payments following delivery verification
Delivery Schedule
Delivery schedule to be finalized; bidders should be prepared for on-site repair within Udhampur region and prompt diagnostics
Penalties/Liquidated Damages
LD clauses to be specified in tender; expect penalties for delays or non-compliance with security requirements
Bidder Eligibility
-
Demonstrated UAV/drone repair experience with verifiable prior projects
-
Compliance with ISI/IS standards or equivalent security clearances (to be confirmed)
-
Ability to operate within Jammu & Kashmir and provide on-site service
Tender Data
Bid Details
Quantity
1
Similar Category
Repair and Overhauling Service
Bid Type
Two Packet Bid
Bid Validity
60 (Days)
Bid Type
Service
Evaluation
Total value wise evaluation
Tech Clarification Time
2 Days
Preference & Exemptions
EMD Required
No
MII Compliance
Yes
MSE Purchase Preference
Yes
MSE Preference Band
L1+15%
MSE Exemption/Relaxation
No
Startup Exemption/Relaxation
No
Bid Splitting Applied
No
Requirements
Arbitration Clause
No
Mediation Clause
No
Additional Tender Data
Commercial Details
Tender Category
Service
Bid To RA
No
Bid To RA Enabled
No
Item Category
Custom Bid for Services - repiar of UAV Drone
Delivery Details
Delivery Locations
1
Delivery Cities
Udhampur
Delivery Locations
| Consignee | Address | City | State | Pincode | Quantity | Delivery Days | Additional Requirement |
|---|---|---|---|---|---|---|---|
| - | Udhampur | Udhampur | - | - | Project / Lumpsum Based | - | - |
Authority Records
BID & GeM Expert Consultancy
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Documents 13
GeM-Bidding-9990014.pdf
Main Document
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
Categories
1
Required Documents
GST Registration Certificate
PAN Card
Experience Certificates ( UAV/drone repair experience )
Financial Statements (last 1-2 years)
EMD/Security Deposit (as per ATC/ Corrigendum)
Technical Bid Document/Methodology
OEM Authorization/Service Provider Certification (if required)
Frequently Asked Questions
Key insights about JAMMU AND KASHMIR tender market
How to bid for UAV drone repair tender in Udhampur Jammu & Kashmir 2026
Bidders must submit certificates per Buyer Added Terms, including GST, PAN, and UAV service credentials. The estimated value is ₹110,000; ensure EMD and technical documentation align with ATC requirements. Prepare to demonstrate prior drone repair capability and security clearances specific to military procurement.
What documents are required for UAV repair tender in Udhampur JK
Required documents include GST certificate, PAN, experience certificates in UAV repair, financial statements, EMD documents, technical bid, and OEM authorizations if applicable. Upload all certificates as per bid terms; non-submission risks rejection by Indian Army procurement.
What are the UAV repair specifications for this Indian Army bid
Technical data currently shows no formal specs; prepare to offer diagnostics, on-site repair, parts replacement, and maintenance with security-compliant processes. Be ready to align with military standards and OEM service requirements once ATC specifies exact UAV models.
When is the delivery and service timeline for UAV repair
Exact delivery timelines will be defined in the final bid package; bidders should anticipate on-site repair within the Udhampur region and rapid diagnostic turnaround, with milestones to be confirmed in the ATC.
What are the EMD and payment terms for this UAV tender
EMD amount is not disclosed in the basic data and will be specified in ATC; payment terms typically involve post-service payment, contingent on verification of work completion and acceptance by Indian Army authorities.
What eligibility criteria apply to UAV maintenance bidders in JK
Eligibility includes demonstrable UAV repair experience, ability to operate in Jammu & Kashmir, compliance with security/certifications, and submission of required documents such as GST, PAN, and financial statements. OEM authorizations may strengthen eligibility.