Bid Publish Date
06-Jun-2026, 8:59 pm
Bid End Date
24-Jun-2026, 5:00 pm
EMD
₹4,500
Location
Progress
Quantity
1
Bid Type
Two Packet Bid
MVVNL (Madhyanchal Vidyut Vitaran Nigam Limited) Lucknow invites bids for the fabrication, erection and installation of UV-stabilized high-density polyethylene anti-kite/bird netting on 33/11 KV lines at Rae Bareli, Uttar Pradesh 229001. Estimated value is not disclosed; EMD amount is ₹4,500. The project scope covers protective netting to deter avian interference on transmission infrastructure. The contract emphasizes field fabrication and on-site installation under MVVNL supervision, with emphasis on durable UV stability and clear, tensioned netting. This is a focused civil/installation work within the distribution network protection domain.
Product/service names: UV-stabilized HDPE anti-kite bird netting
Categories: Fabrication erection & installation on 33/11 KV lines
Estimated value: Not disclosed
EMD amount: ₹4,500
Location: Rae Bareli, Uttar Pradesh
Experience requirement: Not specified; infer capability in live-line protective netting
Standards/certifications: Not specified in data; bidders should reference MVVNL ATC
EMD amount of ₹4,500 to accompany bid documents
Site is Rae Bareli, Uttar Pradesh; work on 33/11 KV lines
No BOQ; installation scope depends on MVVNL specifications and ATC terms
Not explicitly defined in data; bidders should await MVVNL ATC for milestone or advance terms
No dates provided; bidders must align with MVVNL project planning and safety window for live-line work
Not specified; refer to ATC document for potential penalties or LD terms
Experience in HDPE netting installation or related civil/structural protective works
Demonstrated ability to undertake on-site fabrication and erection near HV infrastructure
Financial capacity to mobilize field teams for Rae Bareli works and provide bid security
Tender Category
Service
Bid To RA
No
Bid To RA Enabled
Yes
Item Category
Custom Bid for Services - FABRICATION NERECTION & INSTALLATION OF UV STABILIZED HIGH DENSITY POLY ETHYLENE MADE ANTI KITE FLYING / ANTI BIRD NET ON 33/11 KV -525100
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Main Document
SCOPE_OF_WORK
PAYMENT
OTHER
OTHER
ATC
GEM_GENERAL_TERMS_AND_CONDITIONS
Food Corporation Of India (fci)
KACHCHH, GUJARAT
Indian Navy
ERNAKULAM, KERALA
Indian Navy
ERNAKULAM, KERALA
Indian Navy
ERNAKULAM, KERALA
Mod Sectt Establishment
Tender Results
Loading results...
Discover companies most likely to bid on this tender
GST registration certificate
Permanent account number (PAN) card
Experience certificates for similar HDPE netting installations
Financial statements demonstrating bidder stability
EMD submission proof (₹4,500)
Technical bid documents highlighting installation capability
OEM authorizations or supplier confirmations for UV-stabilized HDPE nets
Extended Deadline
24-Jun-2026, 5:00 pm
Opening Date
24-Jun-2026, 5:30 pm
Key insights about UTTAR PRADESH tender market
Bidders must submit GST, PAN, and EMD ₹4,500 along with technical and financial bids. The scope covers fabrication/erection of UV-stabilized HDPE bird nets on 33/11 KV lines. Review MVVNL ATC for installation standards, safety requirements, and on-site deployment timelines before submission.
Required documents include GST certificate, PAN card, experience certificates for similar netting works, financial statements, EMD proof of ₹4,500, technical bid documents detailing installation capability, and OEM authorizations for UV-stabilized HDPE nets.
Specific mesh size, thickness, UV stabilization grade, and anchoring hardware are not disclosed. Bidders should present standard HDPE anti-kite netting specifications and demonstrate compatibility with 33/11 KV infrastructures, plus safety-compliant installation methodology per MVVNL ATC.
Exact delivery dates are not provided. Respondents should anticipate alignment with MVVNL project scheduling and live-line safety protocols; coordinate installation phases with utility outage windows as specified in the ATC document.
Bid security comprises an EMD of ₹4,500. Submit via online or DD as per tender terms. Ensure validation with bid submission portal or MVVNL requests contained in the ATC to avoid disqualification.
Eligibility includes prior experience in protective netting or live-line compatible installations, financial credibility demonstrated by statements, and capability to mobilize field teams for Rae Bareli works. OEM authorization for UV-stabilized nets strengthens bid positioning.
While specific standards are not listed, bidders should demonstrate MVVNL safety compliance, standard HDPE installation practices, and adherence to live-line safety guidelines as referenced in the ATC document for this tender.
Review the ATC thoroughly to identify mandatory installation methods, anchoring details, safety procedures, and any specialClauses or penalties. Align bid technicals with those requirements; ensure all documents reflect ATC-guided standards.
Mvvnl
📍 RAEBARELI, UTTAR PRADESH
Mvvnl
📍 RAEBARELI, UTTAR PRADESH
Mvvnl
📍 RAEBARELI, UTTAR PRADESH
Mvvnl
📍 RAEBARELI, UTTAR PRADESH
Tamil Nadu Warehousing Corporation
📍 CHENNAI, TAMIL NADU
Sign up now to access all documents
Main Document
SCOPE_OF_WORK
PAYMENT
OTHER
OTHER
ATC
GEM_GENERAL_TERMS_AND_CONDITIONS